Justia Construction Law Opinion Summaries

In 2004, K-Con entered into a contract with the federal government to construct a Coast Guard building in Port Huron Michigan for $582,641. Once K-Con finished, the government imposed liquidated damages of $109,554 for tardiness of 186 days in completion. KCon sued, seeking remission of the liquidated damages on two grounds—that the contract’s liquidated-damages clause was unenforceable and that KCon was entitled to an extension of the completion date. KCon also requested additional compensation based on work performed in response to government requests that K-Con alleges amounted to contract changes. The Court of Federal Claims held that the contract’s liquidated damages clause was enforceable; that K-Con did not comply with the written-notice precondition for invoking the contract clause governing changes; and that K-Con’s claim for an extension on the completion date must be dismissed for lack of jurisdiction. The Federal Circuit affirmed. K-Con failed to comply with the changes clause, and its after-the-fact speculations about what would have happened had it complied do not create a genuine dispute of material fact regarding whether it should be excused for its failure. View "K-Con Bldg. Sys., Inc. v. United States" on Justia Law

During a highway paving project a storm caused recently applied primer to emulsify in rainwater. The oil splashed onto passing vehicles, causing damage. The vehicle owners brought claims against the State, which the State paid. A.M. Welles, Inc. (Welles), the general contractor on the job, reimbursed the State for what it paid to the vehicle owners. The State then sued Liberty Mutual Fire Insurance Co. (Liberty), the insurer for the job, seeking indemnification for the costs that Welles did not cover. Welles, in turn, sued the subcontractors for the project, Montana Materials, Inc., RSJ, Inc., and GLJ, Inc. (collectively, “Jensen”), seeking indemnification under the subcontract. The district court granted summary judgment for Jensen on Welles’s indemnification claim and dismissed the State’s action against Liberty for failure to prosecute. The Supreme Court vacated and remanded, holding that the district court (1) erred in denying Welles’s motion for summary judgment, as Welles was entitled to indemnification under the subcontract; and (2) abused its discretion by dismissing the State’s action against Liberty for failure to prosecute. Remanded. View "A.M. Welles, Inc. v. Mont. Materials, Inc." on Justia Law

Christopher Walton and Tammara Duhn hired Jacob Hatch and his construction company (collectively, Hatch) as the general contractor to build a custom home in a subdivision. Hatch drew up two proposed written contracts, but Walton and Duhn would not sign either one. Nevertheless, construction began. A dispute over what Walton and Duhn owed Hatch led Hatch to terminate his involvement in the project before the house was finished. Walton and Duhn sued Hatch for breach of contract, among other claims. The district court entered judgment in favor of Walton and Duhn and awarded damages. The Supreme Court reversed in part and affirmed in part, holding that the district court (1) erred in calculating the damages that Walton and Duhn suffered as a result of Hatch’s improper billing practices; (2) erred in finding liability and awarding damages for breach of an implied warranty that the home would be built in a skillful and workmanlike manner; and (3) did not abuse its discretion in denying Walton’s and Duhn’s application for attorney fees. View "Walton v. Hatch" on Justia Law

Property owner Crescent City Property Partners, L.L.C., and a builder, Greystar Development and Construction, LP, entered into a contract in March, 2002 for the construction of a mixed-use development in Lafayette. Alleging defects in the builder's performance, and pursuant to the arbitration clause in the construction contract, Crescent filed an arbitration claim against Greystar in 2008, also naming as a defendant Greystar's surety, American Manufacturers Mutual Insurance Company. In response, Greystar filed a third party demand against various subcontractors. The Supreme Court granted writs in consolidated cases to consider whether the court of appeal correctly vacated the arbitration award, which had been confirmed by the district court. The court of appeal vacated the award on the basis the arbitration panel, in applying a statute of peremption incorrectly, disturbed a vested right of the plaintiff and, thus, the panel violated the plaintiff's due process rights. The court of appeal found the arbitration panel's interpretation of the law placed an impossible burden on the plaintiff, a burden the panel deemed fundamentally unfair, thereby requiring vacatur of the arbitration panel's award. After its review, the Supreme Court found that the court of appeal essentially misinterpreted the laws concerning arbitration, and, thus, erred in failing to limit its review to the factors mandating vacatur articulated in La. Rev. Stat. 9:4210. In reversing the court of appeal's decision, the Court reiterated well-settled law that otherwise fairly and honestly obtained arbitration awards may not be overturned merely for errors of fact or law. View "Crescent Property Partners, LLC v. American Manufacturers Mutual Insurance Co." on Justia Law

FTR has constructed buildings for public entities for 15 years. In 1999, FTR submitted the winning bid of $7.345 million to construct a District school. During construction, FTR submitted approximately 150 proposed change orders (PCO). FTR claimed some were necessary because the District’s plans were inadequate or misleading. The District denied most of the PCOs on the grounds that the work was covered under the basic contract, the amounts claimed were excessive, or that a PCO was not timely under the contract. Construction was completed in 2001. Public Contract Code 7107 allows a public entity to withhold funds due a contractor when there are liens on the property or a good faith dispute concerning whether the work was properly performed. The court of appeal held that the trial court properly assessed penalties against District because it did not timely release retained funds; properly rejected the District's action under the False Claims Act, Government Code 12650; and properly assessed prejudgment interest. The court erred in its interpretation of a contract provision imposing time limitations to submit claims for extra work as requiring a showing of prejudice and erred in awarding fees for work not solely related to FTR's section 7107 cause of action. View "FTR Int'l, Inc. v. Rio Sch. Dist." on Justia Law

Plaintiff purchased a home from Laux. Almost two years later, she sued the homebuilder, Shapell for strict liability, negligence, and fraudulent concealment, claiming Shapell built the home on unstable and uncompacted “fill” soil and with an inadequate foundation, causing “substantial differential movement” and numerous defects such as cracked floors, walls, and ceilings. The court granted Shappel summary judgment as to fraudulent concealment and later and entered judgment for Shapell on the other claims, concluding plaintiff lacked standing because her claims accrued when Laux owned the home and he did not assign the claims to plaintiff. The court of appeal reversed. Construing the facts in a light most favorable to plaintiff, there is a triable issue of material fact regarding whether Shapell fraudulently concealed information about the property’s soil conditions. Plaintiff was entitled to have a jury determine the disputed factual issues of when and to whom the causes of action accrued. View "Stofer v. Shapell Indus., Inc." on Justia Law

Metropolitan National Bank agreed to finance construction of a residential subdivision. As security for the note, Ruskin Heights executed a mortgage on the real property in favor of Metropolitan. The afternoon after construction commenced, Metropolitan filed its mortgage. Approximately two years later, Crafton, Tull, Sparks & Associates, Inc. (CTSA) filed an engineering lien against the property. Metropolitan filed a foreclosure complaint against Ruskin Heights and others. CTSA then filed a complaint asserting an engineer’s lien against Ruskin Heights and an amended complaint against Ruskin Heights and Metropolitan, requesting that its lien be declared superior to Metropolitan’s mortgage lien. The cases were consolidated. The circuit court concluded that CTSA’s lien was second in priority to Metropolitan’s lien. CTSA appealed, arguing that its lien should relate back to the commencement of construction and have priority over Metropolitan’s mortgage pursuant to Ark. Code Ann. 18-44-110. The Supreme Court affirmed, holding that Metropolitan’s lien did not have priority over CTSA’s engineer’s lien because section 18-44-110 does not allow for an engineer’s lien to relate back to the date of construction. View "Crafton Tull Sparks & Assocs., Inc. v. Ruskin Heights, LLC" on Justia Law

The issue this case presented for the Supreme Court's review centered on a challenge to the State Liquor Control Board's spirits distribution licensing fee structure brought by Association of Washington Spirits and Wine Distributors (Association). Specifically, the Association challenged the Board's decision to exempt distillers who distribute their own manufactured spirits and others acting as distributors pursuant to certificates of approval from contributing to a shortfall of $104.7 million in licensing fees imposed on persons holding spirits distributor licenses. The Association asked the Supreme Court to hold that the distillers must contribute proportionately to eliminating the shortfall. The Court rejected the Association's arguments, holding that the Board acted within its authority and did not act arbitrarily or capriciously. Additionally, the Board did not violate the privileges and immunities clause of article I, section 12 of the Washington State Constitution. View "Ass'n of Wash. Spirits & Wine Distribs. v. Liquor Control Bd." on Justia Law

Bellingham Marine hired Major Engineering to construct a travel lift pier at the Channel Islands Harbor. Bellingham hired Moffatt, a civil engineering firm, to prepare the plans, which required that the concrete have a specific air entrainment and that the concrete, when cured, attain a specific compressive strength. Major's contract with Bellingham provided that if the concrete failed to meet the compression strength standard, that it would be removed and replaced at Major's expense. Major hired State, which submitted a concrete mix design. Moffatt, at the request of Major, reviewed and approved the design. It was not part of Moffatt's job duties. State delivered seven truck loads of wet pre-mixed concrete. After the concrete was cast, Major's testing lab took a sample that showed the concrete had inadequate compressive strength. Major demolished and rebuilt the affected portion of the pier. It sued; State filed a cross-complaint for implied equitable indemnity and contribution, alleging that Moffatt failed to use reasonable care in reviewing and approving the mix design. The court dismissed, finding that Moffatt was not in privity of contract with Major or State and that the cross-complaint was barred by the economic loss rule. The court of appeal affirmed. View "State Ready Mix Iv. Moffatt & Nichol" on Justia Law

In 1988, Defendant pled guilty to sexual intercourse without consent and was sentenced to thirty years imprisonment with ten years suspended. In 1992, Defendant escaped from prison. After he was apprehended, he was convicted with escape and other charges. In 2007, Defendant was discharged to serve the suspended portion of his sentence. In 2011, the district court orally found that Defendant had substantially violated the conditions of his parole. The court then imposed a new sentence of ten years with all time suspended and imposed fourteen new conditions to Defendant’s suspended sentence. Thereafter, the district court revoked Defendant’s suspended sentence, sentenced Defendant to ten years imprisonment with five years suspended, and reimposed the fourteen new conditions on his suspended sentence. The Supreme Court affirmed, holding that the imposition of fourteen new conditions on Defendant’s suspended sentence for his 1988 crime did not violate ex post facto principles. Remanded. View "State v. Piller" on Justia Law