Justia Construction Law Opinion Summaries

In this case, Nova Group/Tutor-Saliba (“NTS”) was awarded a construction contract by the United States Department of the Navy to build a new aircraft carrier maintenance pier at a naval base. The contract required NTS to demolish an old pier, design and build a replacement pier, and construct a new structure known as the Mole Quaywall, which would be designed by the government. During construction, NTS encountered unexpected subsurface soil conditions that complicated and increased the cost of the project. NTS sought additional compensation from the government alleging differing site conditions.The United States Court of Appeals for the Federal Circuit affirmed the decision of the United States Court of Federal Claims which had denied NTS's claim for additional compensation. The Court of Federal Claims found that NTS had not established a Type I differing site condition because the contract documents disclosed that NTS would encounter unpredictable subsurface conditions and possible obstructions. It also found that NTS had failed to prove a Type II differing site condition, as it had not demonstrated that any of the potential causes for hard driving were unknown or unusual in the region or materially different from comparable work. The Court of Appeals agreed with these findings and also ruled that the parol evidence rule had not been violated as NTS claimed. The Court of Appeals found that the parol evidence rule does not prevent a party from presenting evidence that a recital of fact in an integrated agreement may be untrue, and the challenged evidence was not introduced to modify any term of the contract. Therefore, the appeal by NTS was denied and the decision of the Court of Federal Claims was affirmed. View "NOVA GROUP/TUTOR-SALIBA v. US " on Justia Law

In 2003, the government awarded Parsons a $2.1 billion indefinite-delivery, indefinite-quantity contract for planning and construction work to be described in subsequent task orders. In 2005, the government issued a $34 million task order to complete an existing, concept-level design and construct the Temporary Lodging Facility and Visiting Quarters, at the McGuire Air Force Base. Design and construction were completed. The Air Force accepted the completed facilities for “beneficial use” in September 2008. In 2012, Parsons submitted a claim for approximately $34 million in additional costs that Parsons allegedly incurred in the design and construction process. The Armed Services Board of Contract Appeals awarded Parsons about $10.5 million plus interest.The Federal Circuit reversed in part after holding that the Board had Contracts Dispute Act jurisdiction 41 U.S.C. 7102(a)(1), (3). The court dismissed Parsons’ appeal as to its payroll claim and reversed the Board’s denial of recovery to Parsons for its claim to construction costs. On remand, the Board must award Parsons the difference between its cost in constructing a substituted design compared to the cost Parsons would have incurred in constructing a structural brick design. The court affirmed the Board’s conclusion that Parsons’ costs awarded by the Board were reasonable. View "Parsons Evergreene, LLC v. Secretary of the Air Force" on Justia Law

In 2007, the VA sought to lease space for a Parma, Ohio VA clinic. A pre-solicitation memorandum stated that the building must comply with the Interagency Security Committee (ISC) Security Design Criteria. The subsequent Solicitation discussed the physical security requirements. Premier submitted a proposed design narrative that did not address those requirements. In 2008, Premier and the VA entered into a Lease. Premier was to provide a built-out space as described in the Solicitation. About 18 months later, the VA inquired about Premier’s first design submittal, advising Premier to obtain access to the ISC standards, because “the project needs to be designed according to the ISC.” The ISC denied Premier’s request, stating that the documents had to be requested by a federal contracting officer who has a “need to know.” The VA forwarded copies of three ISC documents. Some confusion ensued as to which standard applied. The VA then instructed Premier to disregard the ISC requirements and to incorporate the requirements from the latest VA Physical Security Guide. Months later, the VA changed position, stating that “[t]he ISC is the design standard.” Premier’s understanding was that only individual spaces listed in a Physical Security Table needed to comply with the ISC. The VA responded that the entire building must conform to the ISC at no additional cost. Premier constructed the building in accordance with the ISC standards then unsuccessfully requested $964,356.40 for additional costs. The Federal Circuit affirmed summary judgment in favor of the government. The contract unambiguously requires a facility conforming to ISC security requirements. View "Premier Office Complex of Parma, LLC v. United States" on Justia Law

Meridian contracted to construct the Chula Vista Project flood control project, including construction of concrete channels, relocation of a sewer line, and dewatering and water diversion. After commencing work, Meridian encountered problems relating to “a layer of dripping saturated dark clay material under which a clean layer of sand is producing water” with “the potential for serious structural damage.” The government issued contract modifications, including an increase in funds for larger pipe, addition of a reinforced concrete access ramp, investigation of soil properties, remediation of saturated soils, and additional sheet piling. The government directed Meridian to suspend work following structural failures and terminated the project following a final inspection. Meridian sued for breach of contract, breach of the duty of good faith and fair dealing, and violation of the Contract Disputes Act, 41 U.S.C. 601−613. The government conceded liability for certain costs relating to suspension of work, channel fill, and interim protection. With respect to other claims, the Federal Circuit affirmed in part. Meridian’s interpretation of the contract was not reasonable; the existence of subsurface saturated soil conditions was “reasonably foreseeable.” The Trade Court did not impose an improper requirement for investigation of site conditions beyond what a reasonable contractor would undertake. The court remanded for consideration of whether the parties reached a meeting of the minds on flood event claims and held that the Trade Court erred dismissing Meridian’s unpaid contract quantities claim, in light of conflicting information. View "Meridian Engineering Co. v. United States" on Justia Law