Justia Construction Law Opinion Summaries

The Cote Corporation filed a mechanic’s lien against real property owned by Kelley Earthworks, Inc. Cote subsequently brought a complaint to enforce the lien against Kelley. Kelley did not respond to the complaint or to Cote’s motion for summary judgment. The superior court entered Kelley’s default and then entered judgment for Cote, plus interest and attorney fees, and ordered that the property be sold to satisfy the judgment. Kelley appeared ten days after the judgment was entered on the docket and filed motions to set aside its default and for relief from the judgment. The court declined to set aside the default but did strike its order to sell the real property, instead awarding Cote a money judgment. The Supreme Court vacated the judgment, holding that the court erred in striking the provision of its order requiring a sale of the property. Remanded for entry of an order for the sale of at least a portion of Kelley’s land. View "The Cote Corp. v. Kelley Earthworks, Inc." on Justia Law

The Fillers planned to demolish an unused Chattanooga factory. They knew the site contained asbestos, a hazardous pollutant under the Clean Air Act. Environmental Protection Agency regulations require removal of all asbestos before any demolition. Asbestos materials must be wetted, lowered to the ground, not dropped, labeled, and disposed of at an authorized site. Fillers hired AA, a certified asbestos surveying company, which estimated that it would cost $214,650 to remove the material safely. Fillers hired Mathis to demolish the factory in exchange for salvageable materials. Mathis was required to use a certified asbestos contractor. Mathis applied for an EPA demolition permit, showing an estimated amount of asbestos far less than in the AA survey. The agency’s asbestos coordinator contacted Fillers to verify the amount of asbestos. Fillers did not send the survey, but provided a revised estimate, far less than the survey’s estimate. After the permit issued, the asbestos contractor removed “[m]aybe, like, 1/100th” of the asbestos listed in the AA survey. Temporary laborers were hired, not equipped with protective gear or trained to remove asbestos. Fillers supervised. The work dispersed dust throughout the neighborhood. An employee of a daycare facility testified that the children were unable to play outside. Eventually, the EPA sent out an emergency response coordinator and declared the site an imminent threat. Mathis and Fillers were convicted of conspiracy, 18 U.S.C. 371, and violations of the Clean Air Act, 42 U.S.C. 7413(c). Fillers was also convicted of making a false statement, 18 U.S.C. 1001(a)(2), and obstruction of justice, 18 U.S.C.1519. The district court sentenced Mathis to 18 months’ imprisonment and Fillers to 44 months. The Seventh Circuit affirmed.View "United States v. Mathis" on Justia Law

The Gagnards built a house in Los Altos, California, then sold the home to Goldman in January, 2004. Since then, Goldman has sued the Gagnards and those involved with the construction and sale of the house in various tribunals. In 2011, Goldman registered a foreign arbitral award in Illinois. She then sought citations to discover and collect assets. The district court issued denied reconsideration motions and granted a turnover order. After filing an appeal, the Gagnards paid $1.3 million to Goldman in satisfaction of the judgment. Goldman accepted the payment, and refunded money she had collected in excess of the judgment balance. The district discharged all pending citations and allowed the Gagnards to file a counterclaim against Goldman, claiming unjust enrichment, but subsequently dismissed the counter-complaint. The Seventh Circuit affirmed, based on the failure, by the Gagnards to act in a timely manner. View "Goldman v. Gagnard" on Justia Law

American General Contractors, Inc. ("AGC"), appealed a judgment assessing liability and awarding damages and interest for the cost of delays in the construction of the Williams County Law Enforcement Center in Williston. C&C Plumbing and Heating, LLP ("C&C"), the successful bidder for the mechanical prime contract, filed suit when construction the center was delayed approximately two years after "substantial completion" was supposed to have happened. The district court concluded it was appropriate for the County and AGC to share responsibility for providing temporary shelter and heat on the project. The court apportioned 47 percent of the liability for the costs of the delay for the three and one-half months of active interference to the County and 53 percent to AGC, for the four months delay inherent to the industry. The court awarded C&C approximately $73,000 on its claim against the County. After offsetting amounts owed between the parties, the court awarded AGC approximately $424,000 on its claim against the County. The court awarded Davis Masonry approximately $96,000 from AGC for masonry work completed under its subcontract with AGC, and rejected AGC's claimed offsets to that amount. Davis had provided heat, cover and shelter for the project during cold weather and sought $649,000 from the County and AGC for that expense including prompt payment interest. Davis had settled with the County for $530,000, and the court ruled AGC was responsible for 53 percent of the remaining $119,000, or $63,070. AGC argues the district court erred in determining AGC was liable for any of the costs incurred from the delay under its contract with the County. Finding no reversible error, the Supreme Court affirmed the district court. View "C&C Plumbing and Heating, LLP v. Williams County" on Justia Law

In 2005, John Block purchased property in Lewiston from Jack Streibick to develop. Block submitted an application to resubdivide the property into three residential lots, which Lewiston approved. Prior to Block's purchase of the property, Lewiston issued two separate permits to Streibick allowing him to place and grade fill in the area of those lots. In 2006, Block received permits from Lewiston to construct homes on each of the three lots. During construction of the homes, Block hired engineering firms to test compaction of the finished grade for the footings on the lots. Following the construction of the homes, Lewiston issued Block certificates of occupancy for each of the homes after conducting inspections that found the homes to be constructed in accordance with applicable building codes and standards. In April 2007, Block sold the home and property at 159 Marine View Drive. In November of that year, the owner reported a crack in the home's basement. Around that same time, settling was observed at the other two properties. In early December 2007, Block repurchased 159 from the owners. He also consulted with engineers regarding options for immediate repair to the homes. As early as February 2009, further settling problems were reported at the properties. After Lewiston inspected the properties in May following a gas leak at 153, it posted notice that the residential structures on 153 and 159 were unsafe to occupy. Block ultimately filed a Notice of Claim for Damages with Lewiston that also named City Engineer Lowell Cutshaw as a defendant, but did not effectuate process on Lewiston and Cutshaw until ninety days had elapsed from the date he had filed the Notice of Claim. The City defendants filed a motion for summary judgment, arguing that Block's claims should be dismissed because he failed to timely file a Notice of Claim with Lewiston. This first motion for summary judgment was denied because a question of material fact existed concerning whether Block reasonably should have discovered his claim against Lewiston prior to 2009. The City defendants filed a second motion for summary judgment seeking dismissal of all of Block's claims against them, arguing that they were immune from liability for all of these claims under the Idaho Tort Claims Act (ITCA) and that Block could not establish that he was owed a duty. The district court granted this second summary judgment motion dismissing Block's claims based on the application of the economic loss rule. The court also held that immunity under the ITCA and failure to establish a duty provided alternate grounds for dismissal of Block's claims. Block appealed on the issue of immunity. Finding no reversible error as to that issue, the Supreme Court affirmed the district court's decision. View "Block v. City of Lewiston" on Justia Law

Plaintiff, acting as subcontractor to Builder, performed work on a property in the City of Providence owned by Owner and leased by Lessee. A dispute subsequently arose regarding payment, and Plaintiff sought to enforce a mechanics’ lien against Owner, Lessee, and Builder. After Owner and Lessee deposited a bond, with Liberty Mutual Insurance Company as surety, the superior court discharged the lien. Plaintiff subsequently amended its complaint to add Liberty as a defendant. Plaintiff then moved for partial summary judgment on the mechanics’ lien claim. The trial justice denied Plaintiff’s motion for summary judgment and entered final judgment in favor of Owner and Lessee. Plaintiff appealed, arguing that the superior court erred in entering judgment in favor of Owner and Lessee because they, as well as Builder and Liberty, were all directly liable to it for any rights it had under the lien statute. The Supreme Court affirmed, holding that the plain language of the mechanics’ lien statute mandates the dismissal and discharge of the lien once a bond, which replaces the property as security for the claim, is deposited with the registry of the court. View "Nat’l Refrigeration, Inc. v. Capital Props., Inc." on Justia Law

ROK Builders LLC (ROK) constructed a hotel for Moultonborough and had a mechanic's lien on the property. 2010-1 SFG Venture LLC (SFG) was the assignee of the construction lender and had a mortgage on the hotel. After Moultonborough filed for bankruptcy, SFG initiated an adversary proceeding against ROK in bankruptcy court, seeking a declaration that its mortgage was senior to ROK's lien to the extent the construction lender had disbursed loan funds to ROK. ROK, in turn, asserted that its lien was senior to SFG's mortgage. The New Hampshire bankruptcy court and district court entered judgment in favor of SFG. The First Circuit Court of Appeals affirmed, holding that the bankruptcy court did not err in concluding that N.H. Rev. Stat. Ann. 447:12-a established the seniority of SFG's mortgage over ROK's mechanic's lien to the extent of the amount of money the construction lender disbursed to ROK. View "ROK Builders, LLC v. 2010-1 SFG Venture, LLC" on Justia Law

Plaintiff, a subcontractor, filed an action to enforce a mechanic's lien on certain land. More than a year later, Defendants, acting as principal debtor and the surety, executed and recorded a surety bond to dissolve the lien pursuant to Mass. Gen. Laws. ch. 254, 14. The bond named Plaintiff as an obligee. Plaintiff subsequently amended its complaint to include Defendants as defendants in the underlying complaint and to add a claim to enforce the bond against them. At issue was whether Plaintiff's amendment of its original complaint constituted timely commencement of its action to enforce a bond pursuant to section 14. The lower court found that although Plaintiff had not filed the amended complaint within ninety days of receipt of notice of the bond, service of its motion to amend on Defendants within that ninety-day period satisfied the section 14 requirement that a claimant have "commenced" a civil action within that period in order to enforce the bond. The Supreme Court affirmed, holding that the commencement requirement in section 14 was satisfied on the facts of this case because the amendment to the complaint related back to the date on which Plaintiff filed its original action against Corporation. View "Nes Rentals v. Me. Drilling & Blasting, Inc." on Justia Law

Lakeview Reserve Homeowners Association filed an action against Maronda Homes for breach of the implied warranties of fitness and merchantability, also referred to as the implied warranty of habitability in the residential construction context. The underlying cause of action arose from alleged defects in the construction and development of a residential subdivision that Maronda Homes and T.D. Thomson Construction Company developed. Lakeview Reserve served as the homeonwers association of the division. Maronda Homes filed a third-party complaint against T.D. Thomson for indemnification based on the alleged violations by Maronda Homes. The trial court entered summary judgment in favor of Maronda Homes and T.D. Thompson, finding that the common law implied warranties of fitness and merchantability do not extend to the construction and design of the private roadways, infrastructure, or any other common areas in a residential subdivision. The court of appeal reversed, holding that the common law warranty of habitability applied in this case. The Supreme Court affirmed, holding that the implied warranties of fitness and merchantability applied to the improvements that provided essential services to the homeowners association. Remanded. View "Maronda Homes, Inc. of Fla. v. Lakeview Reserve Homeowners Ass'n" on Justia Law

The Town of Kearny hired Brandt-Kuybida Architects to design and plan the construction of a new public safety facility. Construction began in 1994. The general contractor, Belcor Construction, signed a "Certificate of Substantial Completion" in late 1995. Approximately ten days later, the architects signed the same Certificate. The Certificate defined the date of substantial completion in language similar to that of the construction contract. The signatories to the Certificate, however, left the "date of issuance" and the "date of completion" of the project blank. In Spring1996, the Town's Construction Official issued the first Temporary Certificate of Occupancy (TCO), limited to the police section of the building. Structural defects in the facility surfaced shortly after the Kearny Police Department took occupancy, including leaks, buckled tiles and cracks in the walls. By 2007, ceilings in the facility had fallen and pipes had separated and pulled, all of which were attributed to uneven settlement. The Town never issued a final certificate of occupancy and on February 8, 2007, had the building vacated. Belcor initiated arbitration proceedings against the Town because the Town withheld final payment under the contract. Belcor and the Town resolved their dispute by Stipulation of Settlement. Both the Stipulation of Settlement and the related Town of Kearny Resolution identified the date of substantial completion of the facility as February 1, 1996. The issues before the Supreme Court were: (1) when could a building be considered substantially complete for purposes of calculating the ten-year period of the statute of repose; and (2) whether the Comparative Negligence Act and the Joint Tortfeasors Contribution Law authorized the allocation of fault to defendants who obtained dismissals pursuant to the statute of repose. The Supreme Court concluded after review that (1) the ten year period of the statute of repose started when the first Temporary Certificate of Occupancy was issued for the facility; and (2) when the claims against a defendant are dismissed on statute of repose grounds, fault may be apportioned to the dismissed defendant under the Comparative Negligence Act and the Joint Tortfeasors Contribution Law. View "Townof Kearny v. Brandt" on Justia Law