Justia Construction Law Opinion Summaries

Articles Posted in Government Contracts
by
In this case, Nova Group/Tutor-Saliba (“NTS”) was awarded a construction contract by the United States Department of the Navy to build a new aircraft carrier maintenance pier at a naval base. The contract required NTS to demolish an old pier, design and build a replacement pier, and construct a new structure known as the Mole Quaywall, which would be designed by the government. During construction, NTS encountered unexpected subsurface soil conditions that complicated and increased the cost of the project. NTS sought additional compensation from the government alleging differing site conditions.The United States Court of Appeals for the Federal Circuit affirmed the decision of the United States Court of Federal Claims which had denied NTS's claim for additional compensation. The Court of Federal Claims found that NTS had not established a Type I differing site condition because the contract documents disclosed that NTS would encounter unpredictable subsurface conditions and possible obstructions. It also found that NTS had failed to prove a Type II differing site condition, as it had not demonstrated that any of the potential causes for hard driving were unknown or unusual in the region or materially different from comparable work. The Court of Appeals agreed with these findings and also ruled that the parol evidence rule had not been violated as NTS claimed. The Court of Appeals found that the parol evidence rule does not prevent a party from presenting evidence that a recital of fact in an integrated agreement may be untrue, and the challenged evidence was not introduced to modify any term of the contract. Therefore, the appeal by NTS was denied and the decision of the Court of Federal Claims was affirmed. View "NOVA GROUP/TUTOR-SALIBA v. US " on Justia Law

by
Stronghold and the city entered into a 2015 contract to renovate the Monterey Conference Center. Before filing a lawsuit asserting a claim for money or damages against a public entity, the Government Claims Act (Gov. Code 810) requires that a claim be presented to the entity. Without first presenting a claim to the city, Stronghold filed suit seeking declaratory relief regarding the interpretation of the contract, and asserting that the Act was inapplicable.Stronghold presented three claims to the city in 2017-2019, based on its refusal to approve change orders necessitated by purportedly excusable delays. Stronghold filed a fourth amended complaint, alleging breach of contract. The court granted the city summary judgment, reasoning that the declaratory relief cause of action in the initial complaint was, in essence, a claim for money or damages and that all claims in the operative complaint “lack merit” because Stronghold failed to timely present a claim to the city before filing suit.The court of appeal reversed. The notice requirement does not apply to an action seeking purely declaratory relief. A declaratory relief action seeking interpretation of a contract is not a claim for money or damages, even if the judicial interpretation sought may later be the basis for a separate claim for money or damages which would trigger the claim presentation requirement. View "Stronghold Engineering, Inc. v. City of Monterey" on Justia Law

by
Baldwin County Bridge Company, LLC ("BCBC"), filed suit against John Cooper in his official capacity as Director of the Alabama Department of Transportation ("ALDOT"), seeking to halt construction of a bridge that ALDOT had hired Scott Bridge Company, Inc. ("Scott Bridge"), to build over the Intracoastal Waterway in Baldwin County. That lawsuit spawned three matters before the Alabama Supreme Court. In the first, Cooper sought mandamus relief because the trial court entered an order compelling him to respond to certain discovery requests made by BCBC; he argued the information sought was protected from disclosure by the executive-privilege doctrine. On Cooper's motion, the Supreme Court stayed enforcement of the trial court's discovery order to allow the Court to consider Cooper's privilege argument. Meanwhile, the trial-court proceedings continued and, before the Supreme Court was able to rule on Cooper's mandamus petition, the trial court granted BCBC's motion for a preliminary injunction to halt construction of the bridge. Cooper appealed that injunction, arguing that it was unwarranted and that the $100,000 preliminary-injunction bond put up by BCBC was insufficient. Scott Bridge filed its own appeal challenging the preliminary injunction, while also arguing that the trial court erred by dismissing it from the case and by stating that it was not entitled to the protection of an injunction bond. After reviewing the briefs submitted by the parties in all three of these matters, the Supreme Court concluded BCBC's claim on which the preliminary injunction was based was barred by State immunity. Accordingly, the trial court had no subject-matter jurisdiction over that claim and the preliminary injunction had to be reversed. Although the Court ruled in favor of Cooper on this point, it nevertheless rejected his companion argument that the trial court should have been directed to increase the $100,000 preliminary-injunction bond on remand. The Court also rejected Scott Bridge's argument that that it was entitled to recover on the preliminary-injunction bond. Finally, because the discovery that Cooper sought to withhold based on executive privilege was being sought in conjunction with the claim that is barred by State immunity, the trial court's order compelling Cooper to produce that information was moot, as was Cooper's petition challenging that order. View "Ex parte Alabama Department of Transportation" on Justia Law

by
Construction firm Brasfield & Gorrie, LLC, received the prime contract to expand the University of Mississippi Medical Center Children’s Hospital in 2017. Electrical contractor McInnis Electric Company secured the winning bid to install the electrical and low voltage systems package for the project and subsequently signed a subcontract with Brasfield & Gorrie. Terms of the subcontract incorporated the prime contract, which were related to the same project by reference. The contract provided that work was set to begin on the project on February 15, 2018. However, McInnis, was directed not to report on site until June 4, 2018, and, due to delays, was unable to begin until July 23, 2018. As work progressed, the schedule allegedly became delayed as a result of Brasfield & Gorrie’s failure to coordinate the work of the various subcontractors. McInnis averred that Brasfield & Gorrie’s failure to coordinate and facilitate the work of the various subcontractors worsened as the project progressed, and Brasfield & Gorrie experienced turnover in management. This failure allegedly delayed McInnis’s work, which was not on the path toward completion, supposedly through no fault of its own. Construction issues were amplified when on March 11, 2020, Mississippi experienced its first reported case of COVID-19. On April 1, 2020, the Mississippi Governor instituted a shelter in place order in response to the ongoing pandemic, requiring certain nonessential businesses to close and recommending social distancing to reduce the spread of the coronavirus in Mississippi. The children’s hospital was not classified as an existing infrastructure as it was a nonoperational work in progress and thus was not subject to the executive order’s exception to the governmental shutdowns. By May 8, 2020, McInnis had suffered an approximately 40 percent loss in its workforce due to employees testing positive for COVID-19. Despite the decrease in the available workforce, Brasfield & Gorrie demanded McInnis perform under its contractual obligation. McInnis took measures to continue the work. Brasfield & Gorrie further declined requests for accommodation and instead terminated McInnis on May 13, 2020. The case before the Mississippi Supreme Court here stemmed from disagreements and a broken contract between the parties, contesting whether arbitration was appropriate to settle their disputes. The trial court compelled arbitration, and the Supreme Court affirmed. View "McInnis Electric Company v. Brasfield & Gorrie, LLC et al." on Justia Law

by
In 2018, Kousisis and Alpha Painting were convicted of conspiracy to commit wire fraud, 18 U.S.C. 1349, and three counts of wire fraud, 18 U.S.C. 1343. The charges arose from false documents filed concerning “disadvantaged business enterprise” status in transportation construction projects for which the U.S. Department of Transportation provided funds through the Federal Highway Administration to the Pennsylvania Department of Transportation. The district court imposed a 20-point sentencing enhancement under U.S.S.G. 2B1.1(b)(1), which corresponds to a loss of $9.50 million-$25 million, noting that the actual loss to the government was not measurable at the time of sentencing and concluding that Alpha’s “ill-gotten profits” represented an appropriate measure of loss.The Third Circuit affirmed the convictions. The defendants secured PennDOT’s money using false pretenses and the value PennDOT received from the partial performance of those painting and repair services is no defense to criminal prosecution for fraud. The court vacated the calculation of the amount of loss for sentencing purposes, noting the extreme complexity of the case. The victim’s loss must have been an objective of the fraudulent scheme; it is insufficient if that loss is merely an incidental byproduct of the scheme. The court separately vacated a forfeiture order of the entire profit amount on the contracts. View "United States v. Alpha Painting & Construction Co., Inc." on Justia Law

by
After submitting the winning bid, Eagle Rock Timber, Inc. (“Eagle Rock”), contracted with Teton County, Idaho to reconstruct a stretch of road known as “Chapin Lane.” During the course of the project, Eagle Rock claimed it discovered unsuitable base material under portions of the road. Eagle Rock maintained that Teton County’s agent, Darryl Johnson, directed Eagle Rock to remove the material and said that the county would “make it right.” However, when Eagle Rock attempted to recover an amount in excess of the original Contract Price, Teton County denied Eagle Rock’s request, stating that it had not authorized any changes to the Contract. When the parties could not resolve this dispute over the amount owed, Eagle Rock filed suit. Teton County twice moved for summary judgment. The district court denied the first motion, concluding that genuine issues of material fact existed concerning whether Johnson orally waived the writing requirement and whether Johnson had authorized Eagle Rock to remove the unsuitable base material, which could support an equitable remedy. In the County's second motion, the district court granted it, ruling that since Teton County’s agent did not have actual or apparent authority to bind Teton County, the claims asserted by Eagle Rock failed as a matter of law. Eagle Rock appealed, asserting that the district court erred because there were still genuine issues of material fact that should be resolved by a jury. Further, Eagle Rock claimed the district court’s refusal to grant leave to amend its complaint to assert a separate cause of action against Johnson personally was an abuse of discretion. After review, the Idaho Supreme Court reversed the district court’s grant of summary judgment and denial of leave to amend. However, the Court affirmed the district court in not considering the ratification issue because it was beyond the scope of the pleadings at the time it was presented. View "Eagle Rock Timber, Inc. v. Teton County" on Justia Law

by
Decedent was employed by Jones as a construction worker. Jones was under contract with DOT to perform construction work on I-580 in Oakland. Much of this work was performed at night because it required lane closures. A car operated by a drunk driver entered the closed lanes of the project site and struck Decedent, who died on the scene. A wrongful death lawsuit against DOT asserted vicarious liability for the negligence of its employees; failure to discharge a mandatory duty; and dangerous condition on public property. The court dismissed the mandatory duty claim. DOT offered evidence that it did not instruct or control Jones as to how to comply with its safety obligations but that Jones complied with its safety plan on the night in question and that the contract between DOT and Jones delegated to Jones the responsibility for selecting the means for performing, including ensuring worker safety.The trial court concluded DOT was not liable for Decedent’s death as a matter of law because DOT delegated to Jones its duty to provide a safe work environment and the conduct of the drunk driver was not reasonably foreseeable. The court of appeal affirmed, rejecting arguments that admissible evidence was wrongfully excluded. Plaintiffs failed to present evidence that DOT retained control over the construction site and actually exercised that control in such a way as to affirmatively contribute to Decedent's injuries, as required under California law. View "Marin v. Department of Transportation" on Justia Law

by
A general contractor hired a subcontractor to provide material for a project at a state park. After the project was completed, the general contractor sent the subcontractor a check described as “final payment.” The subcontractor, believing it was owed more, initially refused to accept the check. Months later, the subcontractor cashed the check but then attempted to repay the amount to the general contractor. The general contractor refused repayment, claiming that the subcontractor’s cashing the check constituted satisfaction of its claim of payment. The superior court granted summary judgment to the general contractor, ruling that the evidence established an accord and satisfaction. The Alaska Supreme Court held there was a genuine dispute of material fact about two requirements for an accord and satisfaction: whether the payment was tendered in good faith, and whether there was a bona fide dispute about the amount owed. The superior court's judgment was therefore vacated, and the case remanded for further proceedings. View "Smallwood Creek, Inc. v. Build Alaska, LLC" on Justia Law

by
In a case of first impression, the Pennsylvania Supreme Court granted review to determine whether the Commonwealth Court properly calculated the “cost” of steel products under the Steel Products Procurement Act (“Steel Act” or “the Act”), which required that “75% of the cost of the articles, materials and supplies [of a steel product] have been mined, produced or manufactured” in the United States. G. M. McCrossin, Inc. (“McCrossin”), a contracting and construction management firm, served as the general contractor for the Lycoming County Water and Sewer Authority (“Authority”) on a project known as the Montoursville Regional Sewer System Waste Water Treatment Plan, Phase I Upgrade (“Project”). In July 2011, McCrossin entered into an agreement with the Authority to supply eight air blower assemblies, which move air from one area to another inside the waste treatment facility. United Blower, Inc. (“UBI”), became a subcontractor on the Project. UBI was to supply the eight blowers required by the original specifications and was to replace the three digestive blowers as required by a change order. UBI prepared a submittal for the blowers which McCrossin in turn submitted to the Authority’s Project engineer, Brinjac Engineering (“Brinjac”). As part of the submittal, McCrossin provided Brinjac and the Authority with a form, which verified that 75% of the cost of the blowers was attributable to articles, materials, and supplies (“AMSs”) that were mined, produced, or manufactured in the United States. The total amount McCrossin paid UBI for the blower assemblies and digestive blowers was $239,800. The amount paid by the Authority to McCrossin for these items was $243,505. Authority employees began to question whether McCrossin and UBI provided products that complied with the Steel Act. The Supreme Court held the Commonwealth Court improperly calculated the cost of the steel products at issue, thereby reversing and remanding for further proceedings. View "United Blower, et al. v Lycoming Water & Sewer" on Justia Law

by
The Court of Appeals affirmed the decision of the Maryland State Board of Contract Appeals (MSBCA) granting summary disposition as to the Maryland State Highway Administration's (SHA) claims against Brawner Builders, Inc. and Faddis Concrete Products, Inc., holding that there was no error in the MSBCA's decision to grant SHA's motion for summary decision.SHA and Brawner entered into a contract for the construction of noise barriers along a section of interstate. Faddis manufactured noise wall panels for Brawner's use in connection with the project. SHA subsequently suspended approval of Faddis-produced noise panels. Faddis filed a procurement contract claim. The MSBCA issued summary disposition to the SHA, concluding that Faddis had no standing to file such a claim. At issue on appeal was whether Faddis's status as a "pre-approved supplier" of concrete panels on construction projects administered by the SHA constituted a "procurement contract" with the State under the State Finance and Procurement Article. The circuit court reversed. The court of special appeals reversed the circuit court. The court of Special Appeals affirmed, holding that the MSBCA properly dismissed Faddis's claims and entered judgment in SHA's favor. View "Brawner Builders, Inc. v. Maryland State Highway Administration" on Justia Law