Justia Construction Law Opinion Summaries

The Town of Kearny hired Brandt-Kuybida Architects to design and plan the construction of a new public safety facility. Construction began in 1994. The general contractor, Belcor Construction, signed a "Certificate of Substantial Completion" in late 1995. Approximately ten days later, the architects signed the same Certificate. The Certificate defined the date of substantial completion in language similar to that of the construction contract. The signatories to the Certificate, however, left the "date of issuance" and the "date of completion" of the project blank. In Spring1996, the Town's Construction Official issued the first Temporary Certificate of Occupancy (TCO), limited to the police section of the building. Structural defects in the facility surfaced shortly after the Kearny Police Department took occupancy, including leaks, buckled tiles and cracks in the walls. By 2007, ceilings in the facility had fallen and pipes had separated and pulled, all of which were attributed to uneven settlement. The Town never issued a final certificate of occupancy and on February 8, 2007, had the building vacated. Belcor initiated arbitration proceedings against the Town because the Town withheld final payment under the contract. Belcor and the Town resolved their dispute by Stipulation of Settlement. Both the Stipulation of Settlement and the related Town of Kearny Resolution identified the date of substantial completion of the facility as February 1, 1996. The issues before the Supreme Court were: (1) when could a building be considered substantially complete for purposes of calculating the ten-year period of the statute of repose; and (2) whether the Comparative Negligence Act and the Joint Tortfeasors Contribution Law authorized the allocation of fault to defendants who obtained dismissals pursuant to the statute of repose. The Supreme Court concluded after review that (1) the ten year period of the statute of repose started when the first Temporary Certificate of Occupancy was issued for the facility; and (2) when the claims against a defendant are dismissed on statute of repose grounds, fault may be apportioned to the dismissed defendant under the Comparative Negligence Act and the Joint Tortfeasors Contribution Law. View "Townof Kearny v. Brandt" on Justia Law

Richard and Lisa Keane and the companies they managed, and Bald, Fat & Ugly, LLC (BFU) had a disagreement arising from a development deal involving the Houston Professional Plaza. They went to mediation, but the parties had a disagreement regarding the terms of the mediated agreement. They then turned to arbitration. The arbitrator granted two awards in favor of BFU. The award did not specify any date by which the Keanes were to pay the money, nor did the award include interest. The district court confirmed the arbitration awards, and issued a writ of execution. The sheriff returned the writ not satisfied. BFU then obtained an order for a debtor's examination. A partial satisfaction of judgment was made, but the Keanes did not direct how the payment made was to be applied to the two arbitration awards. BFU applied the partial satisfaction to one of the awards, and filed a motion to have the Keanes held in contempt for failing to pay the second. The Keanes challenged the contempt action. The Supreme Court, after its review of the matter, found that because the order confirming the arbitration award did not require the Keanes to do anything and because contempt cannot be used to enforce payment of the debt in this case, the Court reversed the judgment of the district court finding them in contempt and the order later entered awarding the respondent attorney fees and court costs. View "Bald, Fat & Ugly v. Keane" on Justia Law

RICS executed a note secured by a mortgage on real estate. Meanwhile, TLA entered into a contract with RICS to provide architectural and engineering services for the project and recorded two documents related to its work on the project. Subsequently, TLA filed a petition to enforce its mechanics' lien. No claimant timely entered an appearance in TLA's mechanics' lien litigation to preserve the priority of their claims. Months later, Petra purchased the note and mortgage, which had not been recorded by the previous owner. Meanwhile, the superior court entered a consent order signed by RICS and TLS in the mechanics' lien litigation. RICS subsequently conveyed the property, and the court placed the property into receivership. Petra later filed a motion to file an answer and statement of claim out of time in the mechanics' lien proceedings. The court granted the motion, thereby restoring the mortgage's priority over TLA's mechanics' lien. The property was sold to Petra through a receivership action. The Supreme Court reversed the superior court's grant of Petra's motion, thereby restoring the priority of TLA's mechanics' lien, holding that the motion justice erred in determining that Petra's failure to file a timely statement of claim was the result of "excusable neglect." View "R.I. Constr. Servs., Inc. v. Harris Mill, LLC" on Justia Law

Plaintiff sold a parcel of land adjacent to a golf club to New South Properties (New South) for development as a residential community. New South hired Hunter Construction Group (Hunter) to prepare the parcel for construction. Hunter built erosion control structures and devices, including a silt collection basin. However, a dam Hunter constructed to form the silt collection basin ruptured, causing mud, water, and debris to flood the golf course. As a result of the damage to the golf course, Plaintiffs filed an action against New South, Apple Creek and Hunter, alleging negligence, nuisance, trespass, and violations of the Sedimentation Pollution Control Act (SPCA). The trial court granted summary judgment to Defendants on the SPCA claim. Plaintiffs appealed and withdrew their appeal against all defendants except Hunter. The court of appeals affirmed. Without considering the merits of Plaintiffs' appeal, the Supreme Court affirmed as modified, holding that because Hunter was never cited for a violation for section 113A-66 of the SPCA, Plaintiffs did not have standing to bring a civil action against Hunter pursuant to section 113A-66. View "Applewood Props., LLC v. New S. Props., LLC" on Justia Law

The issue before the Supreme Court centered on the grant of summary judgment in favor of Respondent Action Concrete Contractors, Inc. in a mechanic's lien foreclosure action. Owners Elvira Chappelear, Craig Chappelear, Premier Southern Homes, LLC, Henry G. Beal, Jr. and First Citizens Bank and Trust Co., Inc. argued on appeal there were material issues of fact and that the grant of summary judgment was inappropriate. The Supreme Court disagreed after its review of the trial court record and affirmed. View "Action Concrete v. Chappelear" on Justia Law

Prince was the general contractor for construction of an apartment building. Rybaltowski was an employee of a waterproofing company. His boss took Rybaltowski to the project site to perform an unpaid demonstration of the proposed caulking of windows. While Rybaltowski was at the site, a beam supporting masonry equipment fell on him. Less than an hour after the accident, Prince signed a subcontract with the waterproofing company. The insurance policy at issue was a Commercial General Liability Insurance policy with an exclusion from coverage for bodily injury to any contractor arising out of or in the course of the rendering or performing services of any kind or nature whatsoever by such contractor. “Contractor” was defined to include employees of subcontractors. The district court entered judgment in favor of the insurer, finding it had no duty to defend. The Seventh Circuit reversed and remanded, reasoning that the policy can be interpreted so that services are not provided until the contractor begins compensated work on the project. View "Atl. Cas. Ins. Co. v. Prince Contractors, Inc." on Justia Law

The Wicks Law requires public entities seeking bids on construction contracts to obtain separate specifications for three subdivisions of the work to be performed. Until 2008 when the law was amended to raise the threshold, the Wicks Law applied to contracts whose cost exceeded $50,000. The new, higher thresholds, unlike the old one, were not uniform throughout the State. Plaintiffs claimed, inter alia, that the amendments violated the Home Rule section of the State Constitution by unjustifiably favoring the eight counties with higher thresholds. Supreme Court dismissed the complaint, holding that Plaintiffs lacked standing to assert the Home Rule cause of action and that, in any event, the challenged amendments did not violate the Home Rule section because they "were enacted in furtherance of and bear a reasonable relationship to a substantial State-wide concern." The Appellate Division affirmed. The Court of Appeals affirmed as modified, holding (1) at least one plaintiff had standing to assert the Home Rule claim, but that claim failed on the merits; and (2) most of Plaintiffs' other claims failed, but four causes of action challenging the apprenticeship requirements as applied to out-of-state contracts should be reinstated. View "Empire State Chapter of Associated Builders & Contractors v. Smith" on Justia Law

Ground Control, LLC appealed the grant of summary judgment in favor of Capsco Industries, W.G. Yates & Sons Construction and Harrah's Entertainment, Inc. The parties contracted to build the "Margaritaville Spa and Hotel" in Biloxi. The circuit court held in part that Ground Control's failure to obtain a certificate of responsibility rendered its contract with Capsco null and void. After its review of the circuit court record, the Supreme Court agreed (and affirmed) that the lack of the certificate of responsibility rendered the contract null and void. However, the Court reversed the grant of summary judgment in part so that the circuit court could determine whether Ground Control was entitled to recover based on claims of unjust enrichment and/or quantum meruit. View "Ground Control, LLC v. Capsco Industries, Inc." on Justia Law

Plaintiffs served as the general contractor and the project developer for construction of a student housing complex at the University of Connecticut (UConn). UConn procured a commercial general liability (CGL) policy for the project, which insured Plaintiffs and their work. Defendant, American Motorists Insurance Company (AMICO), was the issuing insurer's successor in interest. UConn alleged that Plaintiffs breached the agreement with UConn, and Plaintiffs demanded that AMICO defend against UConn's claims. AMICO denied coverage. Plaintiffs settled their claims with UConn and then brought this action against Defendant for breach of contract and bad faith. The U.S. district court certified three questions of law for the Connecticut Supreme Court's consideration. The Court answered (1) allegations of unintended defective construction work by a subcontractor that damages nondefective property may trigger coverage under a CGL policy; (2) under the plain language of the insurance policy in this case, there is no cause of action based on AMICO's failure to conduct a discretionary investigation of claims for coverage; and (3) in global settlements encompassing multiple claims, the insured has the burden of proving that a pre-suit settlement is reasonable in proportion to claims that the insurer has a duty to defend. View "Capstone Bldg. Corp. v. Am. Motorists Ins. Co." on Justia Law

Guardian Builders, LLC, and Wayne Tackett (collectively "Guardian") appealed an order that denied its motion to vacate or modify an arbitration award entered in favor of Randy and Melissa Uselton. In April 2010, the Useltons sued Guardian alleging several claims arising from Guardian's construction of a house. Guardian subsequently filed a motion to compel arbitration, and the circuit court granted that motion. The arbitrator entered a final award in favor of the Useltons in the amount of $452,275.20. Upon review, the Supreme Court construed Guardian's motion to vacate or modify the arbitration award of as a notice of appeal under Rule 71B, thus effectuating the appeal of the award to the circuit court. However, because the clerk of the circuit court never entered the award as the judgment of that court, the circuit court's order denying Guardian's motion to vacate or modify was void. "Essentially, Guardian's appeal remains pending in the circuit court, awaiting further procedures under Rule 71B. Further, because Guardian has appealed from the arbitration award under Rule 71B, that award could not be entered as the judgment of the court under 71C. Thus, the circuit court lacked authority to enter a judgment on the award under Rule 71C and to award Better Business Bureau fees and facility costs in connection with the entry of that judgment." View "Guardian Builders, LLC v. Uselton " on Justia Law