Justia Construction Law Opinion Summaries

Vought sued for the balance due on his contract for the renovation of Stock’s house, additional compensation under a disputed change order, and penalties for the violation of a prompt-payment statute, Civil Code section 8800. Stock did not dispute the unpaid amount Vought had earned for finished work, including approved change orders, but disputed the claim for additional compensation and sought liquidated damages for delay. The court held that Vought was entitled to the undisputed balance due plus approximately half the disputed amount of additional compensation; that Stock was entitled to approximately half the amount he claimed as liquidated damages; and that Stock had not violated section 8800 by withholding final payment. The court held that neither side was entitled to attorney fees under section 8800 or to costs under Code of Civil Procedure section 1032.The court of appeal affirmed in part. Stock was not prohibited from withholding the $79,000 otherwise due based on his good faith claim for liquidated damages. Vought was not relieved of the obligation to pay liquidated damages for the delay that it caused although it was not responsible for the entire delay. Neither party was the prevailing party under section 8800 but Vought was the prevailing party for purposes of recovering costs under section 1032; it secured a “net monetary recovery.” View "Vought Construction Inc. v. Stock" on Justia Law

The Supreme Court affirmed the judgment of the district court regarding several orders unfavorable to Plaintiff in this dispute over the development of a subdivision on property containing a floodplain within Lewis and Clark County, holding that there was no error or abuse of discretion.In its challenged orders, the district court dismissed Plaintiff's negligence and negligent misrepresentation claims, denied Plaintiff's motion for a declaratory judgment that Mont. Code Ann. 76-5-109(4) is unconstitutional, dismissed Plaintiff's claims for inverse condemnation and nuisance, and dismissed Plaintiff's suit against the Montana Department of Transportation. The Supreme Court affirmed, holding that the district court (1) did not err in dismissing Plaintiff's inverse condemnation claim; (2) did not err in dismissing Plaintiff's unjust enrichment claim; (3) did not err in finding Mont. Code Ann. 76-5-109(4) was constitutional; and (4) did not err in dismissing Plaintiff's remaining nuisance claims. View "Hamlin Construction & Development Co. v. Mont. Dep't of Transportation" on Justia Law

The Supreme Court reversed the order entered by the district court denying Skyline Consulting Group's motion to vacate and set aside bond substitution and reinstate construction lien, holding that the district court erred in concluding that Skyline had waived its right to challenge the substitute bond.In this dispute between two subcontractors, Mortensen Woodwork petitioned the district court to substitute Skyline's construction lien against certain property with the intent to pursue foreclosure. Skyline named SP Hotel Owner in the lien. Mortensen then secured a bond from a surety company for 150 percent of the amount Skyline claimed and filed a petition to substitute the bond for the lien. The district court did so. Skyline requested that the district court reinstate its lien because Mortensen was not authorized to substitute a bond. The district court denied the request. The Supreme Court reversed, holding (1) Skyline did not waive its right to challenge the substitute bond in a separate arbitration proceeding; and (2) the district court erred in concluding that Montana law authorized Mortensen, a subcontractor, to substitute a bond for Skyline's construction lien. View "Skyline Consulting Group v. Mortensen Woodwork, Inc." on Justia Law

The Supreme Court affirmed the judgment, decree of foreclosure, and order of sale by the district court, and the orders and actions contained within these documents, holding that there was no error or abuse of discretion.Thermal Design, Inc. filed a complaint to foreclose its construction lien against Mark and Pam Duffy and Central Copters, Inc. The complaint also asserted claims against TNT Building Systems. A jury found that TNT, acting as an agent of Central Copters, entered into a contract with Thermal Design for the insulation system, and both TNT and Central Copters were jointly and severally liable for breaching the contract with Thermal Design. As to a crossclaim between TNT and Central Copters, the jury found that both parties breached their agreement but that only TNT incurred damages. The district court entered a final order restating that, as a matter of law, Thermal Design had a valid construction lien attaching to both the Duffys’ real property and Central Copters’ building that should be foreclosed. The Supreme Court affirmed, holding that the district court did not err or abuse its discretion in the proceedings below. View "Thermal Design, Inc. v. Thorson" on Justia Law

The Supreme Court held that public policy prohibits an agreement between a builder-vendor and a homebuyer to disclaim and waive the warranty of workmanship and habitability implied in every contract entered into between the buyer-vendor and homebuyer and to replace it with an express warranty.Plaintiff entered into a preprinted purchase agreement with M & RC II, LLC to buy a home that M & RC II's affiliate, Scott Homes Development Company, would build. Plaintiff later sued M & RC II and Scott Homes (together, Defendants) for breach of the implied warranty of workmanship and habitability. Defendant moved for summary judgment on the ground that Plaintiff had waived the implied warranty per the purchase agreement. The trial court granted summary judgment for Defendant. The court of appeals reversed. The Supreme Court affirmed, holding that the public policy underlying the implied warranty of workmanship and habitability clearly outweighed enforcement of the waiver of that warranty in the purchase agreement. View "Zambrano v. M & RC II LLC" on Justia Law

Cope, injured on a Kentucky job site, filed a workers’ compensation claim. The subcontractor who hired him for the project, CMC, is based in Southern Indiana, and had an insurance policy with AFICA. Schultheis Insurance Agency procured the policy for CMC, but failed to inform AFICA that CMC did business in Kentucky. AFICA sought a declaration that its policy does not cover Cope’s claim.The district court granted AFICA summary judgment. The Seventh Circuit affirmed. The plain text of the policy is unambiguous: because CMC failed to notify AFICA until after Cope’s accident that it was working in Kentucky, AFICA is not liable for Cope’s workers’ compensation claim. The policy states : “If you have work on the effective date of this policy in any state [other than Indiana], coverage will not be afforded for that state unless we are notified within thirty days.” View "Accident Fund Insurance Co. v. Schultheis Insurance Agency, Inc." on Justia Law

The First Circuit affirmed the judgment of the district court confirming certain damages awarded to The University of Notre Dame (USA) in England (Notre Dame) by a foreign arbitral tribunal in a contractual dispute relating to construction defects, holding that Notre Dame's petition for judicial confirmation of the awards was not time-barred.Notre Dame brought this action against TJAC Waterloo, LLC and ZVI Construction Co., who were, respectively, the seller and renovator of a dormitory that Notre Dame had agreed to purchase. The dispute was submitted to arbitration. After the arbitrator entered the awards, Notre Dame moved the district court to confirm the awards and entered summary judgment in its favor. The district court granted Notre Dame's request for judicial confirmation. The First Circuit affirmed, holding that Notre Dame's motion for judicial confirmation was not time-barred. View "University of Notre Dame (USA) in England v. TJAC Waterloo, LLC" on Justia Law

The Supreme Court affirmed the decision of the circuit court granting summary judgment in favor of a general contractor based on the general contractor's statutory immunity under S.D. Codified Laws 62-3-10, holding that the circuit court properly concluded that workers' compensation was the sole remedy available to Appellant.Plaintiff received a work-related injury at a construction site where his employer was a subcontractor. Plaintiff received workers' compensation benefits from his employer and then filed a negligence claim against the construction project's general contractor. The general contract subsequently amended its answer to assert statutory immunity under section 62-3-10. The circuit court granted summary judgment for the general contractor, concluding that the general contractor remained potentially liable for workers' compensation under S.D. Codified Laws 62-3-10 and, because of the exclusivity provisions of section 62-3-2, workers' compensation was Plaintiff's sole remedy. The Supreme Court affirmed, holding that the circuit court did not err in granting summary judgment for JM. View "Ries v. JM Custom Homes, LLC" on Justia Law

The Supreme Court reversed the decision of the court of appeals affirming the judgment of the trial court granting the motion for judgment on the pleadings filed by defendant Harnett County and dismissing the claims brought by plaintiff PF Development Group and all but one of the claims asserted by the remaining plaintiffs, holding that remand was required.At issue in this case was an ordinance adopted by the County that required residential property developers to pay one-time water and sewer capacity use fees associated with the lots they planned to develop as a precondition for obtaining the County's concurrence in the developer's application for the issuance of required water and sewer permits. In seeking relief from the trial court's orders, Plaintiffs argued on appeal that genuine issues of material fact existed. The court of appeals disagreed and affirmed. The Supreme Court reversed, holding that the "capacity use" fees at issue were "monetary exactions" subject to constitutional scrutiny and therefore must satisfy the "essential nexus" and "rough proportionality" test to avoid being treated as takings of Plaintiffs' property. View "Anderson Creek Partners, L.P. v. County of Harnett" on Justia Law

Plaintiffs Lynn Gerlach and Lola Seals appealed the judgment entered in their action against defendant K. Hovnanian’s Four Seasons at Beaumont, LLC under the Right to Repair Act (the Act), concerning alleged construction defects. After review, the Court of Appeal affirmed and published its opinion to clarify: (1) a roof is a manufactured product within the meaning of California Civil Code section 896(g)(3)(A) only if the roof is completely manufactured offsite; and (2) to prove a roof defect claim under subdivision (a)(4) or (g)(11) of section 896, a plaintiff must prove that water intrusion has actually occurred or roofing material has actually fallen from the roof. View "Gerlach v. K. Hovnanian's Four Seasons at Beaumont, LLC" on Justia Law