Justia Construction Law Opinion Summaries

Border States Paving was awarded the prime contract by the state DOT for a road project. Border States entered into a subcontract with Morris, Inc. for aggregates and work on the project. During work on the project, the DOT orally informed Morris that certain materials passed the soundness test. However, the materials actually failed. Ultimately, the paving was not completed by the seasonal deadline. When the project was completed the next year, the DOT paid Border States in full. Border States withheld several thousand dollars from Morris for costs associated with the project because it believed Morris defaulted in its contractual obligations under the subcontract. Morris brought suit against the DOT, alleging that the DOT breached its express and implied contractual obligations owed to Morris and that the DOT breached its implied contractual obligation of good faith and fair dealing. The circuit court ruled in favor of Morris and awarded Morris damages. The Supreme Court reversed, holding that there was insufficient evidence that the DOT's erroneous pass report proximately damaged Morris where there was no evidence in the record that this error alone caused the project to not get completed by the deadline. View "Morris, Inc. v. State ex rel. Dep't of Transp." on Justia Law

After Leon Coleman failed to perform eight construction contracts for detached homes, he was convicted of eight counts of theft by deception and eight counts of failure to escrow under Deposits on New Homes Subtitle (Act). The court of special appeals reversed, holding that the Act did not apply and that there was insufficient evidence of intent to support the theft convictions. The Court of Appeals affirmed, holding (1) the evidence was insufficient to conclude that Coleman intentionally deprived buyers of their property, as required under the theft statute; and (2) the plain meaning of the Act indicated that it did not apply to Coleman. View "State v. Coleman" on Justia Law

A construction company (Contractor) entered into a contract with the State to restructure an interstate interchange. The contract contained an incentive clause stating that no incentive payment would be made if work was not completed in its entirety by December 15, 2006. After the work was completed, Contractor filed a complaint alleging that the State had breached the contract by refusing to grant an appropriate time extension of the completion date, the disincentive date, and the incentive date. The claims commission (1) found that the contract contained a latent ambiguity requiring extrinsic evidence to interpret the contract, and (2) considered extrinsic evidence in concluding that Contractor was entitled to the maximum incentive payment and an extension of the contract completion date. The court of appeals affirmed. The Supreme Court reversed, holding (1) the contract was unambiguous and did not permit an extension of the incentive date, and (2) therefore, Contractor was not entitled to an incentive bonus. Remanded. View "Ray Bell Constr. Co. v. State" on Justia Law

Plaintiffs sued defendant in contract and tort, alleging that defendant failed to take necessary precautions to protect its premises from water damage. At issue on appeal was the trial judge's decision not to grant prejudgment interest on the amounts that were awarded by the jury to plaintiffs. The court held that plaintiffs were entitled to prejudgment interest as a matter of right and remanded to the Superior Court to determine the amount of prejudgment interest owed. View "Brandywine Smyrna, Inc., et al. v. Millennium Builders, LLC" on Justia Law

The Weitz Company sued MacKenzie House and MH Metropolitan for breach of construction contract. Arrowhead and Concorde were third-party defendants. MH Metropolitan counterclaimed for breach of the same contract, seeking liquidated damages and the cost to complete the project. Arrowhead also counterclaimed. The jury returned a verdict for MH Metropolitan, Arrowhead, and Concorde on Weitz's claim. The district court denied post-judgment motions and Weitz appealed. The court held that there was a legally sufficient evidentiary basis for the jury's verdict; the district court properly exercised its discretion in excluding the evidence of other projects; the district court correctly decided that the issue of liquidated damages and completion costs were issues of fact that were properly submitted to the jury; there was a legally sufficient evidentiary basis for the district court to deny judgment as a matter of law for Weitz's breach-of-contract claims against Arrowhead; the district court did no err in refusing to enter a default judgment against Concorde when it failed to appear at trial, or in the alternative, refusing to grant Weitz judgment as a matter of law on its claims against Concorde; and because the district court properly found against Weitz on all issues, there was no reason to consider the issue of vicarious liability. View "The Weitz Co. v. MacKenzie House, et al." on Justia Law

This case arose out of the 2007 collapse of the Interstate 35W Bridge. Individual plaintiffs commenced lawsuits against two contractors that performed work on the bridge pursuant to contracts entered into with the State. The contractors brought third-party complaints against Jacobs Engineering Group on the basis that Jacobs' predecessor negligently designed the bridge. One contractor also filed a third-party complaint against the State. The State cross-claimed against Jacobs for contribution, indemnity, and statutory reimbursement. Jacobs moved to dismiss the State's cross-claim as time-barred, arguing that the reimbursement provision of the compensation statutes compensating survivor-claimants of the collapse did not retroactively revive causes of action against Jacobs that had been previously extinguished by a prior version of the statute of repose. The district court denied the motion, and the court of appeals affirmed. The Supreme Court affirmed, holding (1) the provision retroactively revived the State's action for statutory reimbursement against Jacobs; (2) the provision did not violate Jacob's constitutional right to due process; and (3) revival of the action for statutory reimbursement did not unconstitutionally impair Jacobs' contractual obligations. View "In re Individual 35W Bridge Litig." on Justia Law

This case arose out of the 2007 collapse of the Interstate 35W Bridge. Individual plaintiffs commenced lawsuits against a contractor that performed work on the bridge pursuant to a contract entered into with the State. The contractor brought a third-party complaint against Jacobs Engineering Group for indemnity and contribution on the basis that Jacobs' predecessor negligently designed the bridge. Jacobs moved to dismiss the lawsuits as time-barred and argued that the 2007 amendments to Minn. Stat. 541.051 did not revive actions for contribution or indemnity that had previously been extinguished by a prior version of the statute of repose. The district court denied the motion to dismiss, but the court of appeals reversed. The Supreme Court affirmed the court of appeals, holding that the 2007 amendments to section 541.051 did not retroactively revive the contractor's action for contribution against Jacobs. View "In re Individual 35W Bridge Litig." on Justia Law

In 2006, Developer-Appellee 500 James Hance Court, LP entered into a construction management agreement with Contractor Gorman Construction Company, Inc., pertaining to the erection of a building at 500 James Hance Court, situated within the Oaklands Corporate Center in Exton, Chester County. According to the agreement, the contemplated, 68,000-square-foot structure was to be used as an elementary charter school, and the project was denominated "Collegium Charter School." Soon after the lease and related contracts were executed, the Bureau of Labor Law Compliance notified the School that it was investigating the project to determine whether prevailing wages were required. In this regard, the Bureau explained that charter school construction was treated the same as a traditional school project (re: public works project) for prevailing wage purposes. If the project's phases could be bifurcated, both the school and Appellee would be responsible. The issue between the parties centered on who was ultimately responsible for compliance with the prevailing wage law: the contractor or the school. The Commonwealth Court had found no evidence that the charter school had any role in determining space and performance goals for the project, and therefore the school was responsible for compliance. But upon review, the Supreme Court concluded that the Board’s determination that the lease was a disguised construction contract for the building as a whole, was based on legal error and essential findings which lacked substantial evidentiary support. Facially, the project was rationally divisible according to major phases of shell and fit-out construction. As to the shell, Appellees established the private character of the funding. Furthermore, in terms of economic reality, Appellees presented a prima facie case that Developer's only relationship with the School was per a bona fide pre-development lease. The Bureau failed to go forward with sufficient evidence to the contrary to overcome this prima facie case, and as such, affirmed the Commonwealth Court. View "500 James Hance Ct. v. Pa. Prevailing Wage Appeals Bd." on Justia Law

Petitioner, a constructor, was sued by several people living in new homes built by Petitioner (Residents). Residents claimed they were injured by radon gas leaking into their homes because of improper construction by Petitioner. Petitioner argued that the agreement to purchase the new homes required Residents to arbitrate their claims, whether they signed the agreement or not. The circuit court found the arbitration provision ambiguous and unconscionable and refused to compel Residents into arbitration. Petitioner subsequently sought a writ of prohibition to compel Residents to arbitrate their claims. The Supreme Court denied the writ, holding that the circuit court was within its authority to refuse to enforce the arbitration clause against Residents because the arbitration provision was ambiguous, unconscionable, and unenforceable. View "State ex rel. Richmond Am. Homes v. Jefferson County Circuit Court (Sanders)" on Justia Law

This case involved a dispute regarding developed property. Developer filed a complaint alleging that the project's general contractor (Contractor) and an engineering firm (Firm) had negligently provided recommendations with respect to site preparation. The circuit court granted partial summary judgment in favor Firm on Contractor's cross-claims against Firm that sought recovery of remediation costs incurred by Contractor, concluding (1) some of Contractor's cross-claims were time-barred by the applicable statute of limitations, and (2) W. Va. Code 55-2-21 did not apply to toll any limitations periods because Contractor's claims were independent causes of action as opposed to cross-claims. The Supreme Court reversed, holding (1) the circuit court prematurely found that section 55-2-21 did not apply because it failed to analyze whether the claims arose from the same transaction or occurrence and, thus, constituted cross-claims or independent causes of action; and (2) genuine issues of material fact existed so as to preclude summary judgment if Contractor's claim was an independent cause of action. Remanded. View "J. A. Street & Assocs. v. Thundering Herd Dev." on Justia Law