Justia Construction Law Opinion Summaries

In this case, Nova Group/Tutor-Saliba (“NTS”) was awarded a construction contract by the United States Department of the Navy to build a new aircraft carrier maintenance pier at a naval base. The contract required NTS to demolish an old pier, design and build a replacement pier, and construct a new structure known as the Mole Quaywall, which would be designed by the government. During construction, NTS encountered unexpected subsurface soil conditions that complicated and increased the cost of the project. NTS sought additional compensation from the government alleging differing site conditions.The United States Court of Appeals for the Federal Circuit affirmed the decision of the United States Court of Federal Claims which had denied NTS's claim for additional compensation. The Court of Federal Claims found that NTS had not established a Type I differing site condition because the contract documents disclosed that NTS would encounter unpredictable subsurface conditions and possible obstructions. It also found that NTS had failed to prove a Type II differing site condition, as it had not demonstrated that any of the potential causes for hard driving were unknown or unusual in the region or materially different from comparable work. The Court of Appeals agreed with these findings and also ruled that the parol evidence rule had not been violated as NTS claimed. The Court of Appeals found that the parol evidence rule does not prevent a party from presenting evidence that a recital of fact in an integrated agreement may be untrue, and the challenged evidence was not introduced to modify any term of the contract. Therefore, the appeal by NTS was denied and the decision of the Court of Federal Claims was affirmed. View "NOVA GROUP/TUTOR-SALIBA v. US " on Justia Law

The Supreme Court of the State of Alaska was asked to determine whether the question of a deceased worker's status as an employee or independent contractor under the Alaska Worker's Compensation Act should be determined by a jury or a judge. The lawsuit was initiated by the estate of Nicholson Tinker, a worker who was killed in a construction accident while working for Mark Welty, doing business as North Country Services. Welty had no workers' compensation coverage at the time of the accident. Tinker's estate argued that he was an employee and that under the Act, Welty was presumed negligent because he had no compensation coverage. Welty argued that Tinker was an independent contractor, hence the Act did not apply.The superior court decided that the question of employee status was an issue for the jury to decide. The estate appealed this decision, arguing that the Supreme Court's earlier decision in Benson v. City of Nenana determined that a judge, not a jury, should decide the issue of a worker's status under the Act.The Supreme Court of the State of Alaska agreed with the estate, holding that the superior court must determine whether Tinker was an employee or independent contractor under the Act as a preliminary issue before trial. The Court reasoned that the applicability of the Act is a legal determination with factual underpinnings that the court should decide as a preliminary matter. The Court also noted that determining the employee status promptly is significant due to its potential impact on basic issues such as the type of action a party can bring or the burden of proof for negligence. Therefore, the Court reversed the superior court’s order that the jury decides the issue of employee status and remanded for further proceedings. View "Leona Seal, Personal Representative of the Estate of Nicholson J. Tinker v. Mark C. Welty D/B/A North Country Services" on Justia Law

In the case before the Supreme Court of the State of Alaska, the petitioner, Eric McDonald, an employee of a subcontractor, suffered injuries during the renovation of a high school. He sued Architects Alaska, Inc. and BBFM Engineers, Inc., alleging that they negligently failed to exercise reasonable care in the design, supervision, implementation, and specifications of the demolition of the renovation project. Before trial, the parties’ attorneys discussed the possibility of a settlement, and the defendants moved to enforce a “walk-away” settlement they claimed had been reached through email correspondence. McDonald, unrepresented at this point, did not file a substantive response to the defendants’ motion. The superior court granted the defendants’ motion and dismissed the case.About a year later, McDonald moved for relief from judgment under Alaska Rule of Civil Procedure 60(b), arguing that he had never given his attorney authority to settle the case. A different superior court judge granted the motion, finding that factual issues precluded summary judgment on whether a settlement agreement existed, that the earlier dismissal was erroneous as a law matter, and that extraordinary circumstances otherwise entitled McDonald to Rule 60(b) relief. The defendants petitioned for review, and the Supreme Court of the State of Alaska reversed the ruling on the ground that McDonald’s Rule 60(b) motion was not filed within a reasonable time. View "BBFM Engineers, Inc. v. McDonald" on Justia Law

Stronghold and the city entered into a 2015 contract to renovate the Monterey Conference Center. Before filing a lawsuit asserting a claim for money or damages against a public entity, the Government Claims Act (Gov. Code 810) requires that a claim be presented to the entity. Without first presenting a claim to the city, Stronghold filed suit seeking declaratory relief regarding the interpretation of the contract, and asserting that the Act was inapplicable.Stronghold presented three claims to the city in 2017-2019, based on its refusal to approve change orders necessitated by purportedly excusable delays. Stronghold filed a fourth amended complaint, alleging breach of contract. The court granted the city summary judgment, reasoning that the declaratory relief cause of action in the initial complaint was, in essence, a claim for money or damages and that all claims in the operative complaint “lack merit” because Stronghold failed to timely present a claim to the city before filing suit.The court of appeal reversed. The notice requirement does not apply to an action seeking purely declaratory relief. A declaratory relief action seeking interpretation of a contract is not a claim for money or damages, even if the judicial interpretation sought may later be the basis for a separate claim for money or damages which would trigger the claim presentation requirement. View "Stronghold Engineering, Inc. v. City of Monterey" on Justia Law

McMurray Contracting, LLC ("McMurray"), appealed a circuit court's denial of its second motion to compel arbitration of this case commenced by Kenneth Hardy and his wife Helen Hardy. The Hardys filed suit in December 2022 alleging they "retained" McMurray to perform restoration work to their house damaged in Hurricane Sally. The Hardys specifically alleged that McMurray "did not complete all restoration work in a good and workmanlike manner, and has refused to correct numerous deficiencies through [the Hardys'] property," and that McMurray "performed work and charged for materials that were never approved." The Alabama Supreme Court found McMurray's notice of appeal was not timely filed so as to invoke the Supreme Court's jurisdiction. Accordingly, it dismissed McMurray's appeal. View "McMurray Contracting, LLC v. Hardy" on Justia Law

In consolidated appeals, the City of Orange Beach ("the City") appealed a judgment entered in favor of Ian Boles in regard to a dispute over the City's inspection of Boles' property. Between 2013 and 2015 Boles constructed two eight-bedroom duplexes on property he owned located within the City limits ("the beachfront property"). In September 2015, Boles filed a building-permit application seeking a permit to construct two additional multiple-level duplexes on the beachfront property. Additionally, in October 2015, Boles filed a separate building-permit application for the construction of a single-family dwelling on another parcel of property that Boles owned within the City limits ("the Burkhart Drive property"). At the time of each permit request, Boles completed a "Home Builders Affidavit" attesting that he was the owner of the property; that he would be acting as his own contractor on the proposed project, which would not be offered for sale; and that he was, thus, exempt from the requirement that he be licensed under Alabama's Home Builders Licensure Law. The building-permit packages provided to Boles explained that a certificate of occupancy for the proposed structure would not be issued until, among other things, "a subcontractor list has been submitted to the [City's] Finance Department." Boles also received with each package a blank subcontractor form for identifying all subcontractors for the proposed project, which specified that it was due within 10 days of the issuance of the building permits. Boles proceeded with construction on the two properties without completing or returning the subcontractor form for either property. Boles's electrical subcontractor apparently contacted the City to request an electrical meter-release inspection upon completion of the electrical portion of that project; the City refused. Boles contended the City either lacked the authority to and/or were exceeding their authority in refusing to inspect the beachfront property until the City received information to which, according to Boles, it was not entitled. The Alabama Supreme Court concluded the trial court erred both in submitting Boles's damages claims to a jury and in denying the City's motion seeking a judgment as a matter of law. The trial court's judgment was reversed, and these matters were remanded for further proceedings. View "City of Orange Beach v. Boles." on Justia Law

Baldwin County Bridge Company, LLC ("BCBC"), filed suit against John Cooper in his official capacity as Director of the Alabama Department of Transportation ("ALDOT"), seeking to halt construction of a bridge that ALDOT had hired Scott Bridge Company, Inc. ("Scott Bridge"), to build over the Intracoastal Waterway in Baldwin County. That lawsuit spawned three matters before the Alabama Supreme Court. In the first, Cooper sought mandamus relief because the trial court entered an order compelling him to respond to certain discovery requests made by BCBC; he argued the information sought was protected from disclosure by the executive-privilege doctrine. On Cooper's motion, the Supreme Court stayed enforcement of the trial court's discovery order to allow the Court to consider Cooper's privilege argument. Meanwhile, the trial-court proceedings continued and, before the Supreme Court was able to rule on Cooper's mandamus petition, the trial court granted BCBC's motion for a preliminary injunction to halt construction of the bridge. Cooper appealed that injunction, arguing that it was unwarranted and that the $100,000 preliminary-injunction bond put up by BCBC was insufficient. Scott Bridge filed its own appeal challenging the preliminary injunction, while also arguing that the trial court erred by dismissing it from the case and by stating that it was not entitled to the protection of an injunction bond. After reviewing the briefs submitted by the parties in all three of these matters, the Supreme Court concluded BCBC's claim on which the preliminary injunction was based was barred by State immunity. Accordingly, the trial court had no subject-matter jurisdiction over that claim and the preliminary injunction had to be reversed. Although the Court ruled in favor of Cooper on this point, it nevertheless rejected his companion argument that the trial court should have been directed to increase the $100,000 preliminary-injunction bond on remand. The Court also rejected Scott Bridge's argument that that it was entitled to recover on the preliminary-injunction bond. Finally, because the discovery that Cooper sought to withhold based on executive privilege was being sought in conjunction with the claim that is barred by State immunity, the trial court's order compelling Cooper to produce that information was moot, as was Cooper's petition challenging that order. View "Ex parte Alabama Department of Transportation" on Justia Law

MSE Building Company, Inc. ("MSE") appealed the grant of summary judgment entered in favor of The Stewart/Perry Company ("Stewart/Perry"); Buc-ee's, Ltd., and Buc-ee's Alabama II, LLC (referred to collectively as "Buc-ee's"); and Philadelphia Indemnity Insurance Company ("Philadelphia"). Among other things, the trial court found MSE's claims against the defendants were unenforceable because MSE had violated § 34-8-1 et seq., Ala. Code 1975, which regulated contractors, by utilizing unlicensed sub-subcontractors in connection with a construction project. After review, the Alabama Supreme Court reversed summary judgment insofar as it determined that MSE's claims were barred as a matter of law under § 34-8-1 because there were material issues of disputed fact regarding whether the labor brokers utilized by MSE were required to obtain a general contractor's license under § 34-8-1. Accordingly, the summary judgment on MSE's lien claim and prompt-payment claim was also reversed. The summary judgment on MSE's negligence claim against Buc-ee's was affirmed. In addition, the summary judgment was affirmed insofar as it was entered in favor of Stewart/Perry on MSE's claims of unjust enrichment and quantum meruit, because MSE did not challenge the judgment on those claims in its appellate brief. View "MSE Building Company, Inc v. The Stewart/Perry Company, et al." on Justia Law

Construction firm Brasfield & Gorrie, LLC, received the prime contract to expand the University of Mississippi Medical Center Children’s Hospital in 2017. Electrical contractor McInnis Electric Company secured the winning bid to install the electrical and low voltage systems package for the project and subsequently signed a subcontract with Brasfield & Gorrie. Terms of the subcontract incorporated the prime contract, which were related to the same project by reference. The contract provided that work was set to begin on the project on February 15, 2018. However, McInnis, was directed not to report on site until June 4, 2018, and, due to delays, was unable to begin until July 23, 2018. As work progressed, the schedule allegedly became delayed as a result of Brasfield & Gorrie’s failure to coordinate the work of the various subcontractors. McInnis averred that Brasfield & Gorrie’s failure to coordinate and facilitate the work of the various subcontractors worsened as the project progressed, and Brasfield & Gorrie experienced turnover in management. This failure allegedly delayed McInnis’s work, which was not on the path toward completion, supposedly through no fault of its own. Construction issues were amplified when on March 11, 2020, Mississippi experienced its first reported case of COVID-19. On April 1, 2020, the Mississippi Governor instituted a shelter in place order in response to the ongoing pandemic, requiring certain nonessential businesses to close and recommending social distancing to reduce the spread of the coronavirus in Mississippi. The children’s hospital was not classified as an existing infrastructure as it was a nonoperational work in progress and thus was not subject to the executive order’s exception to the governmental shutdowns. By May 8, 2020, McInnis had suffered an approximately 40 percent loss in its workforce due to employees testing positive for COVID-19. Despite the decrease in the available workforce, Brasfield & Gorrie demanded McInnis perform under its contractual obligation. McInnis took measures to continue the work. Brasfield & Gorrie further declined requests for accommodation and instead terminated McInnis on May 13, 2020. The case before the Mississippi Supreme Court here stemmed from disagreements and a broken contract between the parties, contesting whether arbitration was appropriate to settle their disputes. The trial court compelled arbitration, and the Supreme Court affirmed. View "McInnis Electric Company v. Brasfield & Gorrie, LLC et al." on Justia Law

The Supreme Court reversed the decision of the court of appeals reversing the conclusion of the trial court that Plaintiff failed to establish Defendant's requisite minimum contacts with Tennessee, and thus the court lacked personal jurisdiction over Defendant with respect to Plaintiff's suit, holding that the trial court correctly dismissed Plaintiff's complaint.Plaintiff, a Tennessee resident, hired Defendant, an Alabama corporation with its principal place of business in Alabama, to build a house on a parcel of land in Alabama. Upon becoming dissatisfied with the quality and expense of the construction work Plaintiff filed suit in the Davidson County Chancery Court. The trial court granted Defendant's motion to dismiss for lack of jurisdiction, concluding that Defendant's contacts with Tennessee were minor and attenuated. The court of appeals reversed. The Supreme Court reversed, holding that Plaintiff failed to establish a prima facie case of the minimum contacts necessary for a Tennessee court to exercise specific personal jurisdiction over Defendant. View "Baskin v. Pierce & Allred Construction, Inc." on Justia Law